Welcome to Elite Customs Designed LLC. These Terms and Conditions ("Terms") govern your use of our services, website, and all interactions with our brand. By engaging our services or accessing our website, you agree to comply with and be bound by these Terms. Please read them carefully before proceeding. If you do not agree to these Terms, you must refrain from using our services or website.
- Introduction
Elite Customs Designed LLC specializes in bespoke interior design services, custom furniture, and renovation solutions. Our goal is to provide exceptional craftsmanship and creative design tailored to meet your needs. These Terms outline the legal agreement between you ("the Client") and Elite Customs Designed LLC ("the Company") and apply to all transactions, agreements, and services provided.
- Scope of Services
Our services include, but are not limited to:
- Residential and commercial interior design.
- Custom furniture design and fabrication.
- Color consultation and space planning.
- Renovation and remodeling services.
The specific details, deliverables, and timelines of each project will be outlined in a formal agreement or contract between the Client and the Company.
- Client Responsibilities
- Provide accurate and complete information regarding your project requirements, preferences, and budget.
- Respond promptly to requests for approvals, feedback, or additional information.
- Fulfill your payment obligations as outlined in the agreement or invoice.
- Grant us access to your property for consultations, measurements, installations, or other project-related tasks, as necessary.
- Project Changes and Revisions
- Pricing and Payment Terms
- Refunds and Cancellations
- Intellectual Property
- Limitations of Liability
- We are not responsible for delays caused by third parties, such as material suppliers, contractors, or unforeseen circumstances (e.g., weather, natural disasters).
- Our liability for damages, losses, or defects is limited to the cost of the specific service or product in question.
- We are not liable for incidental, indirect, or consequential damages resulting from the use or inability to use our services.
- Use of Third-Party Services
- Confidentiality and Privacy
- Sustainability Practices
- Termination of Services
- The Client fails to meet payment obligations or other terms outlined in the agreement.
- The Company is unable to fulfill the scope of work due to circumstances beyond its control.
- Both parties agree to terminate the project by mutual consent.
- Dispute Resolution
- Governing Law
- Amendments to Terms and Conditions
- Contact Information
To ensure the successful completion of your project, we require your full cooperation and timely input. By engaging our services, you agree to:
Failure to meet these responsibilities may result in delays, additional fees, or termination of the agreement.
We understand that design preferences may evolve during the course of a project. Any changes or revisions to the original scope of work must be communicated in writing and may be subject to additional fees or extended timelines.
Once a design or plan has been approved and work has commenced, significant changes to the scope of work (e.g., selecting new materials or altering layouts) may require a formal change order. We will provide an updated estimate and timeline for such changes.
All pricing will be outlined in a detailed estimate or proposal provided prior to the start of the project. Pricing is based on the agreed-upon scope of work, materials, and services.
Payment Schedule
A deposit is required to secure our services and initiate the project. The remaining balance will be billed in installments or upon completion of specific project milestones, as outlined in the agreement. Full payment is required before the delivery of final designs, materials, or completed work.
Late Payments
Invoices not paid by the due date may incur late fees or interest charges. Elite Customs Designed LLC reserves the right to suspend work or terminate the agreement if payment obligations are not met.
Our Refund Policy, which is outlined separately, governs all refund and cancellation requests. Refund eligibility depends on the stage of the project and the nature of the services provided. Please review our Refund Policy for further details.
All designs, plans, and materials created by Elite Customs Designed LLC remain the intellectual property of the Company until full payment is received. Upon full payment, the Client is granted a non-exclusive, non-transferable license to use the designs for the specified project.
Clients may not reproduce, distribute, or use our designs for purposes outside the agreed-upon scope without our prior written consent.
Elite Customs Designed LLC is committed to delivering high-quality results. However, there are limitations to our liability:
Clients are encouraged to communicate any issues promptly so that they can be addressed effectively.
We may collaborate with third-party vendors, contractors, or suppliers to fulfill certain aspects of your project. While we strive to partner with reputable and reliable professionals, Elite Customs Designed LLC is not responsible for the performance, actions, or errors of third parties.
Clients are encouraged to review the terms and warranties provided by third-party vendors or contractors directly.
We are committed to protecting your personal information. Any data shared with us during the course of the project will be handled in accordance with our Privacy Policy.
We may photograph completed projects for marketing or portfolio purposes but will only do so with your prior consent. Personal information, such as your name or address, will not be disclosed without your permission.
Elite Customs Designed LLC is dedicated to sustainable design and sourcing practices. We aim to incorporate environmentally friendly materials and techniques wherever possible. However, the availability and feasibility of sustainable options may vary depending on the specifics of your project.
Clients are encouraged to discuss sustainability goals during the initial consultation to ensure they are incorporated into the design plan.
Either party may terminate the agreement under the following conditions:
Upon termination, the Client will be responsible for paying for all work completed up to the date of termination, as well as any non-refundable deposits or fees.
We are committed to resolving any disputes amicably and professionally. If disagreements arise, both parties agree to engage in good faith discussions to reach a resolution.
In the event that a resolution cannot be reached through direct communication, disputes may be referred to mediation or arbitration, as mutually agreed upon. Legal proceedings should be considered a last resort.
These Terms and any agreements entered into with Elite Customs Designed LLC are governed by the laws of the state in which the Company is registered. Any legal disputes will be subject to the jurisdiction of the courts in that state.
Elite Customs Designed LLC reserves the right to update or modify these Terms at any time. Any changes will be posted on our website, and continued use of our services or website will constitute acceptance of the updated Terms.
If you have questions, concerns, or need clarification about these Terms and Conditions, please contact us:
Elite Customs Designed LLC Email: support@elitecustomsdesigned.comPhone: 1-855-554-6678
Mailing Address: 7950 E Stella Rd 12c, Tucson, AZ 85730, USA
Thank you for choosing Elite Customs Designed LLC. We are committed to delivering exceptional service and creating designs that transform your spaces and elevate your lifestyle.